Claremore Daily Progress

Legal Notices

June 26, 2014

NOTICE TO BIDDERS

CLAREMORE —

Public Notice

PUBLISHED IN THE CLAREMORE DAILY PROGRESS, CLAREMORE, OKLAHOMA, JUNE 26 & JULY 3, 2014.

BIDDING REQUIREMENTS

SECTION 00 11 16 INVITATION TO BID

NOTICE TO BIDDERS

Sealed proposals will be received by the Inola Public Schools, hereinafter referred to as “OWNER”, at the Administration Office 110 North Broadway, Inola, Oklahoma until 2:00 PM, TUESDAY, July 22, 2014, at which time bids will be publicly opened and thereafter contract let to the lowest acceptable bidder for NEW CLASSROOM BUILDING AND ADDITION located 810 East Commercial Street, Inola, Oklahoma.  Reference is made to the site plan for exact location of the building.

Plans and specifications for the above project may be reserved prior to picking up sets by calling Graber and Associates, PC, 2415 East Skelly Drive, Suite 101, Tulsa, Oklahoma, phone (918) 747-8028, Extension 10. A deposit of $50.00 for one (1) set will be required at the time documents are obtained.  Deposit will be returned to unsuccessful bidders provided sets are returned in good condition and within ten (10) working days from bid date.  Sets will be mailed only after a postage and handling fee of $10.00 for one (1) set or $15.00 for two (2) sets has been received by the Architect or the contractors FedEX account could be charged.  All Contractors shall have a current AIA Document 305, “Contractor’s Qualification Statement” or their own company resume and references on file at the Architect’s office or submitted with the Bid Form at the Bid Opening.

Attention is called to the fact that the “Bid Form” designates a time for completion and that the successful bidder will be required to pay the sum of $400.00 per calendar day (Sundays and Holidays included), liquidated damages for each days delay beyond the designated completion date as written on the “Bid Form”.

Each bid shall be accompanied by a bond or certified check payable to the order of Owner, or other security approved by Owner, in an amount of not less than five percent (5%) of the amount of the bid.  This security is given as a guarantee that the bidder to whom the contract is awarded, will enter into a contract with the Owner for the construction of the project, furnish satisfactory statutory and performance bonds, maintenance bonds, and insurance certificate within ten (10) working days after notice of award (unless a longer time is given by Owner in writing), and in the event of failure to do so, there shall be paid to the Owner the sum of five percent (5%) of said bid as liquidated damages.  No bidder may withdraw his bid for a period of forty-five (45) days after opening date.

NO BID WILL BE CONSIDERED UNLESS IT IS SUBMITTED UPON THE FORM OF PROPOSAL PREPARED BY OWNER.  THESE FORMS ARE BOUND IN THIS BOOK.

Owner reserves the right to reject any or all bids and to waive informalities or minor irregularities in any bid.  The Owner also reserves the right to not accept the lowest bid.

INOLA PUBLIC SCHOOLS

INDEPENDENT SCHOOL DISTRICT NO. 5

INOLA, OKLAHOMA

DR. KENT HOLBROOK,

SUPERINTENDENT

 

 

 

1
Text Only
Legal Notices
  • CJ-2014-176

    SUNTRUST MORTGAGE, INC., Plaintiff,

    vs.

    CLEOPHAS L. SIMON, et al., Defendant(s).

    July 31, 2014

  • SOLICITATION FOR BIDS (BID NOTICE)

    Copies of the bid documents are on file at the DCAM/Construction & Properties office and are available for public inspection.

    CAP Project Number: 15014

    Project Name:  OMD Vault Rehabilitation

     

    July 31, 2014

  • Public Notice

    Vehicle Sale

    Sale Date 8/8/14  9:30 AM

    July 31, 2014

  • SOLICITATION FOR BIDS (BID NOTICE)

    Copies of the bid documents are on file at the DCAM/Construction & Properties office and are available for public inspection.

    CAP Project Number: 15003

    Project Name:  Restripe/Repair Minor Cracks Various Parking State-wide Lots

     

    July 31, 2014

  • ADVERTISEMENT FOR BIDS:

    The Grand River Dam Authority, hereinafter called the Owner, will receive Bids on:

    Contract No. 40629

    Transmission Line Construction Services,

    Line Clearance Improvements – L321 & L323

     

    July 31, 2014

  • PB-2014-63

    IN THE MATTER OF THE ESTATE OF: LARRY LEE POTTS

    July 31, 2014

  • CV-2014-74

    IN THE MATTER OF THE APPLICATION OF BABY BOY OSBORNE TO CHANGE HIS NAME, BY AND THROUGH LAWANDA GARMON, HIS NATURAL GRANDMOTHER AND LEGAL GUARDIAN.

     

    July 31, 2014

  • Public Notice

    1979 Lincoln Vin#9Y82S698761
    Charles Hancock 918-639-6114

    July 31, 2014

  • CJ-2013-470

    entitled U.S. Bank National Association, as Trustee, Plaintiff, vs. Rita Jones, Spouse of Rita Jones, if married, Russell Leroy Jones, Ronald E. Berry and St. John Health System, Inc., d/b/a Med Pac, being all of the Defendants and persons holding or claiming any interest or lien in the subject property.

     

    July 30, 2014

  • CJ-2014-61

    FEDERAL NATIONAL MORTGAGE ASSOCIATION (“FANNIE MAE”), A CORPORATION ORGANIZED AND EXISTING UNDER THE LAWS OF THE UNITED STATES OF AMERICA;

    Plaintiff,

    vs.

    KATHRYN E. CARRELL; et al.

    Defendants.

    July 30, 2014